Mike Bubalo Construction Co. Inc.CITY OF ROSEMEAD
GARVEY AVENUE SEWER RELIEF LINE PROJECT
PROJECT No. 21845
BIDDER:
CONTRACT BID FORMS
TABLE OF CONTENTS
SECTION1 BID SCHEDULE ....................................:.................................... ..............................1
SECTION2 BID DATA FORMS ..................................................................... ..............................5
2.A BID BOND .................................................................................. ..............................6
2.13 LIST OF PROPOSED SUBCONTRACTORS ............................ ..............................7
SECTION 3 NON - COLLUSION AFFIDAVIT ................................................. .............................10
SECTION 1 - BID SCHEDULE
CBF -1
BID SCHEDULE
SCHEDULE OF PRICES FOR
GARVEY AVENUE SEWER RELIEF LINE PROJECT
PROJECT No. 21845
BASE BID SCHEDULE
NO.
ITEM DESCRIPTION
UNIT
EST.
QTY.
UNIT
PRICE
ITEM
COST
1
Clearing & Grubbing per Plans and
LS
1
Specifications. See Technical Provisions
Pages TP -2 & TP -3 per Details.
Zt7� 000, or
2
Disposal of Waste Materials.
LS
1
�000,
" *00 '
3
Prepare a Storm Water Pollution
LS
1
_ S
Prevention Plan (SWPPP).
. e
..
-
4
Traffic Control Plans prepared by a
LS
1
Registered Traffic Engineer.
(D
5
Unclassified Excavation.
CY
100
Cap ='
6
Remove and Dispose existing manhole
EA
3
including bedding, backfilling and Paving
per Plans and Specifications Complete.
it _-
T
7
Construct Extra Strength 15 -Inch
LF
2,600
diameter Vitrified Clay Pipe (VCP)
including bedding, backfilling and Paving
per Plans and Specifications Complete.
�/o =
�Zq E7pQ •'•
8
Construct 15 -Inch diameter Ductile Iron
LF
81
(DI) Sewer Pipe including pipe structure
support per SPPWC Std. Plan. 224 -2,
bedding, backfilling and paving per Plans
and Specifications Complete
Z/p$ 2A
2�7 ¢bs. W
9
Remove and Dispose existing 8" Vitrified
LF
330
Clay Pipe (VCP) sewer including pipe
plugs, bedding, backfilling and Paving
per Plans and Specifications Complete.
uj
3� duo
r
10
Construct extra strength 8 -Inch diameter
LF
176
Vitrified Clay Pipe (VCP) including
bedding, backfilling and Paving per
Plans and Specifications Complete.
30 =�
11
Construct Reinforced Precast Concrete
EA
11
Manhole per LACDPW Std. Plan 2003 -2.
! 080, �`
000. -•
CBF -2
TOTAL BASE BID PRICE
u LT_ .o GT
Do llar amount in written form
*P-W
CBF -3
EST.
UNIT
ITEM
NO.
ITEM DESCRIPTION
UNIT
QTY.
PRICE
COST
12
Construct Drop Manhole per CSD Std.
EA
1
Plan S -a -205.
/O wr-
13
Install House Connection Remodeling
EA
41
including pavement per SPPWC Std.
Plan 223 -2
OLi� sir
Z8 GL'i� w
14
House Lateral Replacement per SPPWC
EA
10
Std. Plan 222 -2. *(approx. 25% of
existing laterals)
15
Construct Wye per LACDPW Std. Plan
EA
50
2024 -1.
a
°
-
16
Construct 72" Manhole Type "E" (case II)
LS
1
per CSD Std. Plan S -a -205. And detail
on sheet D1
$. ,_•
ZSL�D r
17
Remodel and plug existing sewer
LS
1
manhole per detail "A" on sheet D1
_•
18
Remove existing and Construct 18"
LS
1
diameter RCP (2000 -D), including
concrete collars per SPPWC Std. Plan.
380-4, complete as shown on the plans
?:sow,
25 O
19
Sewer Flow Bypassing at all locations as
LS
1
shown on the plans.
20
Construct Terminal Cleanout Structure
EA
1
per SPPWC Std. Plan 204 -2
Soo. ^•
S'v®
21
Abandon Existing Sewer. Fill with low
LF
830
density cellular concrete (LDCC) or
controlled low strength material (CLSM)
with min. compressive
q4 (jQ
strength of
3000PSI @ 28day and plug ends
22
Provide temporary and permanent
EA
1
support for the 36" RCP Sewer per CSD
Std. Plan S -a -222 and S -a -217.
Complete in place.
TOTAL BASE BID PRICE
u LT_ .o GT
Do llar amount in written form
*P-W
CBF -3
ALTERNATE BID ITEM 1
BARLETT AVENUE STREET RESURFACING
TOTAL ALTERNATE BID PRICE
Dollar amount in written form
Ce-6
TOTAL BASE & ALTERNATE BID PRICE $ t'i So(;Oi 4�5 - TU
(. A.fzw.dwzW,,5A4wwgb 51pre77mdo gb pLYltfllhoASD wyy 5 DoG444s A7✓
Dollar amount in written form F-D2 ry �
CBF -4
UNIT
EST.
UNIT
ITEM
NO.
ITEM DESCRIPTION
QTY.
PRICE
COST
1
Cold mill 2.0- inches thick existing
SF
91,562
pavement.
62 Zip
18 312,4
2
Construct 2.0 inches thick pavement
TONS
1,170
overlay ARHM -GG -C (PG 64 -16) as
indicated on the plans.
Ct0 x. -'
1 oS�3
3
Remove Existing, Dispose and
SF.
1,200
Construct 4- inches thick PCC Sidewalk
per SPPWC Std. Plan 113 -1.
Z p =
2*
4
Remove Existing, Dispose and
EA
4
Construct PCC Curb Ramps per
SPPWC Std. Plan 1114.
5
Remove Existing and Construct 6-
SF
200
Inches Thick Driveway Approach per
SPPWC Std. Plan 110 -2
6
Adjust Sewer Manhole to Grade per
EA
13
SPPWC Std. Plan 205 -1 and 206 -1.
+ $DO
Z3 �� 2
7
Install Survey Well Monument per City
EA
8
of Rosemead Std. Plan S08 -001. See
Section 2 -9 Surveying of the General
Provision -7 per details (Cover, Sleeve
& Dome will be provided by the City at
no cost).
Eiu/• �"
lP �o.
8
Install Traffic Striping, Traffic Signal
LS
1
Loops and Pavement Markers per the
Striping Plans and Specifications
Complete.
14 Opp
9
Install 36 -Inch Box Parkway Tree Crape
EA
20
Myrtle "Muskogee" including 90 -days
maintenance period and tree wells per
„
z, poo
Xf
SPPWC Std. Plan 520-4.
TOTAL ALTERNATE BID PRICE
Dollar amount in written form
Ce-6
TOTAL BASE & ALTERNATE BID PRICE $ t'i So(;Oi 4�5 - TU
(. A.fzw.dwzW,,5A4wwgb 51pre77mdo gb pLYltfllhoASD wyy 5 DoG444s A7✓
Dollar amount in written form F-D2 ry �
CBF -4
Note: The City of Rosemead reserves the right to reduce or increase the quantities of any items in
the schedule of bid items above, within the limits define in Section 3 -2.2.1 of the Standard
Specifications, to stay within the budgeted amount of this project.
If the Bid Documents specify alternate bid items, the following Alternate Bid amounts shall
be added to or deducted from the Total Bid Price entered above. The owner can choose to
include one or more of the alternates in the Total Bid Price of the Project. If any of the
Alternate Bids are utilized by the Owner, the resulting amount shall be considered the Total
Bid Price for the Project.
The undersigned agrees that these Contract Bid Forms constitute a firm offer to the Owner which
cannot be withdrawn for the number of Working Days indicated in the Notice Inviting Bids from and
afterthe bid opening date, or until a Contract for the Work is fully executed by the Owner and a third
party, whichever is earlier. The undersigned also agrees that if there is a discrepancy between the
written amount of the Bid Price and the numerical amount of the Bid Price, the written amount shall
govern.
Attached hereto is a c eck, a gas . or a bid bond in the amount of
. fgq i 9 e , 6&vA-uf. &t k Dollars ($_LanLj said amount being not less than ten percent (10 %) of the Total
Bid Price. The undersigned agrees that said amount shall be retained by the Owner if, upon award,
we fail or refuse to execute the Contract and furnish the required bonds, certificates and
endorsements of insurance and other certifications within the time provided.
If awarded a Contract, the undersigned agrees to execute the formal Contract, which will be
prepared by the Owner for execution, within five (5) Calendar Days following the Letter of Award for
the Contract, and will deliver to the Owner within that same period the necessary original Certificates
of Insurance, Endorsements of Insurance, Performance Bond, Payment Bond and all other
documentation and certification required by the Contract.
The undersigned offers and agrees that if this bid is accepted, it will assign to the purchasing body
all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton
Act (15 U.S.C. Section 15) or under the Cartwright Act (Chapter 2 of Part 2 of Division 7 of the
Business and Professional Code), arising from purchases of goods, materials or services by the
Bidder for sale to the purchasing body pursuant to the bid. Such assignment shall be made and
become effective at the time the purchasing body tenders final payment to he Contractor.
Bidder understands and agrees that, when requested by Owner, he shall provide: (1) evidence
satisfactory to the Owner of Bidder's California contractor's license(s) in good standing; (2) evidence
that the person signing this Bid is authorized to bind Bidder to this Bid and to a contract resulting
therefrom; and (3) any other information and documentation, financial or otherwise, needed by
Owner to award a Contract to the lowest responsible, and responsive bidder.
CBF -5
Bidder acknowledges that data submitted with its Contract Bid Forms which it requires to be
incorporated into a Contract arising out of this Submittal has been so identified by Bidder. Bidder
further acknowledges that the Owner may, at its discretion, incorporate any of the remaining data
submitted herewith into a contract arising out of this Bid.
The undersigned acknowledges receipt, understanding and full consideration of the following
addenda to the Contract Documents.
Addenda Nos.
The Bidder understands and agrees that the Total Bid Price is inclusive of all labor, materials, and
equipment or supplies necessary to complete the Work as described in the Bid Documents. If this
bid is accepted, the undersigned Bidder agrees to enter into and execute the Contract with the
necessary bonds and accept the Total Bid Price as compensation in full for all Work under the
contract.
CBF -6
By:
ignature
T ype or Print Name
-t;.
Title
1422- P
Business Street Address
City, State and Zip Code
Telephone Number
Bidder's /Contractor's State of Incorporation: k e
Partners or Joint Venturers:
Bidder's License Number(s): 77 /�Z
Department Industrial Relations
Registered No.
NOTES:
1) By its signature on this Bid, the Bidder certifies under penalty of perjury the accuracy of the
representations made on the Contract Bid Forms.
2) If Bidder is a corporation, enter State of Incorporation in addition to Business Address
3) If Bidder is a partnership or joint venture, give full names of all partners or joint
venturers.
As further discussed in the Instructions to Bidders, Bidder will be required
to provide evidence that the person signing on behalf of the corporation,
partnership or joint venture has the authority to do so.
CBF -7
RESOLUTION
OF
Mike Bubalo Construction Co., Inc.
RESOLVED BY THE SHAREHOLDERS of Mike Bubalo Construction Co., Inc., a California
Corporation as follows:
Resolve that Mike Bubalo and Dave Sorem are hereby authorized and directed to execute
Contracts on behalf of and in the name of Mike Bubalo Construction Co., Inc.
This resolution was adopted by the Shareholders of the Corporatist a regular meeting of the
Corporation held on the 29th day of December, 2010 - - --
Director /Shareholder
CERTIFICATE OF SECRETARY
The undersigned hereby certifies that he is the duly elected and qualified Secretary of
Mike Bubalo Construction Co., hic. a California corporation and that the foregoing is a true and
correct record of a resolution(s) duly adopted by the Shareholders of the Corporation on 20th day
of January, 2000.
WHEREOF, I have executed my name as Secretary on 29th day of
IN WITNESS
December, 2010.
SECTION 2
BID DATA FORMS
BIDDER: Mike Bubalo Construction Co., Inc.
Bidder shall submit its Bid data in accordance with the format shown on each of the following Bid
Data Forms. Bidders shall prepare and use as many sheets as are necessary to adequately provide
the information required. Bidder shall ensure that every page of its Bid Data Forms are properly
identified with the Bidder's name and page number.
uwn§ . &
KNOW ALL MEN BY THESE PRESENTS:
THAT Mike Bubalo Construction Co., Inc.
''
Principal, and western Surety Company
as Surety, are held firmly bound unto the
CITY OF ROSEMEAD (hereinafter called the OWNER) in the sum of
Ten Percent of the Total Bid Price
DOLLARS
($ 10% of the total bid price ) , being not less than ten percent (10 %) of the Total
Bid Price; for the payment of which sum will and truly to be made, we bind ourselves,
our heirs, executors, administrators, successors, and assigns, jointly and severally,
firmly by these presents.
WHEREAS, said Principal has submitted a bid to the OWNER to perform all Work
required for the GARVEY AVENUE SEWER RELIEF LINE PROJECT as setforth in
the Notice Inviting Bids and accompanying Bid Documents, dated
July 08, 2015 _
NOW, THEREFORE, if said Principal is awarded a Contract for the Work by the
OWNER and, within the time and in the manner required by the above- referenced
Bid Documents, enters into the written form of Contract bound with said Bid
Documents, furnishes the required bonds (one to guarantee faithful performance
and the other to guarantee payment for labor and materials) furnishes the required
insurance certificates and endorsements, and furnishes any other certifications as
may be required by the Contract, then this obligation shall be null and void; otherwise
it shall remain in full force and effect. In the event suit is brought upon this bond by
the OWNER and judgment is recovered, said Surety shall pay all costs incurred by
the OWNER in such suit, including reasonable attorneys' fees to be fixed by the
court.
SIGNED AND SEALED, this 6 th day of July _ , 20 15 ,
Mike Bubalo Construction Co., Inc. (SEAL)
Prihcip
�d
�d
B � By:
�
W estern Surety Company (SEAL)
Surety
Signature Edith Garibay, Attorney-in-Fact
CBF -9
CALIFORNIA ALL- PURPOSE ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity of the
individual who signed the document to which this certificate is attached, and not the
truthfullness, accuracy, or validity of that document.
State of California
County of Los Angeles f
On JULY 8, 2015 , before me, Anton Brkic,
Notary Public, personally appeared Dave Sorem,
who proved to me on the basis of satisfactory
evidence to be the person whose name is
subscribed to the within instrument and
acknowledged to me that he executed the same in
his authorized capacity and that by his
signature on the instrument the person, or the
entity upon behalf of which the person acted,
executed the instrument.
I certify under PENALTY OF PERJURY under the
laws of the State of California that the
foregoing paragraph is true and correct.
Witness my hand and official seal.
ANTON BRK1C
Commission # 1980971
Z Notary Public - California z
' Los Angeles County n
My Comm. Ex fires Jul 2, 2016 J
c, Notary Public (Notary seal)
CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT
CIVIL CODE § 1189
A notary public or other officer completing this certificate verifies only the identity of the individual who signed the
document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.
State of California
County of Orar
On 0' 7 __ C C_ 3 C _ before me,
Date
personally appeared Edith
Name(s) of Signer(s)
who proved to me on the basis of satisfactory evidence to be the person(sf whose names /W
subscribed to the within instrument and acknowledged to me that the /ttyw� executed the same in
Wher /t�r authorized capacity(ies), and that byme/her/thilir signature�W on the instrument the persorK
or the entity upon behalf of which the person( racted, executed the instrument.
I certify under PENALTY OF PERJURY ender the laws
of the State of California that the foregoing paragraph
is true and correct.
R. RIVAS WITNESS my hand and official-seal.
i 9 y Commission # 1954551
Notary Public - California i
Orange County
n Signature
My Comm. Expires Oct 28, 2015 Signature of Notary Public
Place Notary Seal Above
OPTIONAL
Though this section is optional, completing this information can deter alteration of the document or
fraudulent reattachment of this form to an unintended document.
Description of Attached Document
Title or Type of Document:
Number of Pages:
Document Date:
Signer(s) Other Than Named Above:
Capacity(ies) Claimed by Signer(s)
Signer's Name: Edith Garibay
❑ Corporate Officer — Title(s):
❑ Partner — ❑ Limited ❑ General
❑ Individual ® Attorney in Fact
❑ Trustee ❑ Guardian or Conservator
❑ Other:
Signer Is Representing:
R. Rivas, Notary Public
Here Insert Name and Title of the Officer
Signer's Name:
❑ Corporate Officer — Title(s):
• Partner — ❑ Limited ❑ General
• Individual ❑ Attorney in Fact
❑ Trustee ❑ Guardian or Conservator
❑ Other:
Signer Is Representing:
02014 National Notary Association - www.NationalNotary.org • 1- 800 -US NOTARY (1- 800 - 876 -6827) Item #5907
Western Surety Company
POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN-FACT
Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation
having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby
make, constitute and appoint
William R. Curtis, Rosa E Rivas, Eugene T Zondlo, Edith Garibay, Individually
of Irvine, CA, its true and lawful Attomey(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds,
undertakings and other obligatory instruments of similar nature
- In Unlimited Amounts -
and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said
Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed.
This Power of Attorney is made and executed pursuant to and by authority of the By -law printed on the reverse hereof, duly adopted, as indicated, by
the shareholders of the corporation.
In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be
hereto affixed on this 16th day of June, 2015.
WESTERN SURETY COMPANY
�N 4p0004 l��y
$ rM ORM�
aul T. Brufla[, Vice President
State of South Dakota 1
County of Minnehaha
I as
On this 16th day of June, 2015, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he
resides in the City of Sioux Falls, State of South Dakota; that he is the Vice President of WESTERN SURETY COMPANY described in and which executed
the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed
pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges
same to be the act and deed of said corporation.
My commission expires
JSOUT S. ETCH February 12, 2021 9j NOTARY PUBUC(Ml
DAKOTA l
S. Eich, Notary Public
CERTIFICATE
I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in
force, and further certify that the By -Law of the corporation ponied on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed
my name and affixed the seal of the said corporation Phis Fi, t h day of Jul , 2015_
WESTERN SURETY COMPANY
aoti r ° s
��SE pyrr:.
"xyrN
L. Nelson, Assistant Secretary
Form F4280 -7 -2012
23 LIST OF PROPOSED SUBCONTRACTORS
In compliance with the "Subletting and Subcontracting Fair Practices Act," Sections 4100
through 4114 of the California Public Contract Code, and any amendments thereto, each
Bidder shall provide the information requested below for each subcontractor who will
perform work, labor or render service to Bidder in or about the construction of the Work in an
amount in excess of one -half of one percent (greater than 0.5 %) of the Bidder's Total Bid
Price, or, in the case of bids or offers for the construction of streets or highways, including
bridges, in excess of one -half of 1 percent of the Contractor's total bid or ten thousand
dollars ($10,000), whichever is greater, and shall further set forth the portion of the Work
which will be done by each subcontractor. Bidder shall list only one subcontractor for any
one portion of the Work.
Pursuant to Public Contract Code Section 4104, the Owner has determined that it will allow
Bidders twenty -four (24) additional hours after the deadline for submission of bids to submit
the information requested by the Owner about each subcontractor, otherthan the name and
location of each subcontractor.
If the Bidder fails to specify a subcontractor for any portion of the Work to be performed
under the Contract, it shall be deemed to have agreed to perform such portion itself, and
shall not be permitted to subcontract that portion of the Work except under the conditions
hereinafter set forth below.
Subletting or subcontracting of any portion of the Work in excess of one half of one percent
(greater than 0.5 %) of the Total Bid Price or, in the case of bids or offers for the construction
of streets or highways, including bridges, in excess of one -half of 1 percent of the
Contractor's total bid or ten thousand dollars ($10,000), whichever is greater, for which no
subcontractor was designated in the original bid shall only be permitted in cases of public
emergency or necessity, and then only after Owner approval.
CBF -10
2.6 LIST OF PROPOSED SUBCONTRACTORS (continued)
["Duplicate Next 2 Pages If needed for listing additional subcontractors' "I
Name and Location Description of Work
of Subcontractor to be Subcontracted
License No.:
Department
Name and Location
of Subcontractor
As11U14 7i vld
4,- fAl&
Description of Work
to be Subcontracted
1 rpA .0
Name: �( G� �i✓o L[ G oiR
Address: 2 *t
License N o.: 2 404
Department of Industrial Relation Registration No. o Ap in Z 2
Name and Location
of Subcontractor
Description of Work
to be Subcontracted
Name:
Address:
License No.:
Department of Industrial Relation Registration No.
Name and Location
of Subcontractor
Description of Work
to be Subcontracted
Name:
Address:
License No.:
Department of Industrial Relation Registration No.
Name and Location
of Subcontractor
Description of Work
to be Subcontracted
Name:
Address:
License No.:
Department of Industrial Relation Registration No.
CBF -11
2.0 REFERENCES
The following are the names, addresses and telephone numbers for three public agencies for which BIDDER
has performed similar work within the past two (2) years:
Name and Address
Name and telephone number of person familiar with project
Contract amount Type of Work Date Completed
2.
Name and Address of Owner
Name and telephone number of person familiar with project
Contract amount Type of Work Date Completed
3.
Name and Address of Owner
Name and telephone number of person familiar with project
Contract amount Type of Work Date Completed
4.
Name and Address
Name and telephone number of person familiar with project
amount Type of Work Date Completed
CBF - 12
REFERENCES
Project Name:
Marina Drive Storm Drain
Location: Various streets in along Marina Drive, Seal Beach CA
Owner: City of Seal Beach
Owner Contact (name and current phone number):
David Spitz, P.E.
(562) 431 -2527
Architect or Engineer Contact (name and current phone number):
Psomas, Joe Mulvihill, P.E.
(714) 751 -7573
Construction Manager (name and current phone number):
David Spitz, P.E.
(562) 431 -2527
Description of Project, Scope of Work Performed:
550 LF of double pre cast box
including junction structures, laterals, slurry backfill, groundwater, sewer and water relocations
Total Value of Construction (including change orders): $ 1,519.485.85
Original Scheduled Completion Date: June 2013
Time Extensions Granted (number of days): 42 Days
Actual Date of Completion:
AUG 2013
26
REFERENCES
Project Name:
Valley View Street and Storm Drain
Location: V alley View Street, Cypress
Owner: City of
Owner Contact (name and current phone number):
229 -6729
Architect or Engineer Contact (name and current phone number):
Harris & Assoc., Randall Berry, P.E.
(949) 655 -3900
Construction Manager (name and current phone number):
Nick Mangkalakiri, P.E.
(714) 229 -6729
Description of Project, Scope of Work Performed:
452 LF of 24" RCP, 30 LF
including junction structures, laterals, slurry backfill, groundwater, sewer and water relocations
Total Value of Construction (including change orders): $ 274,218.30
Original Scheduled Completion Date: June 2013
Time Extensions Granted (number of days): Contract was suspen for Value Engineering redesign
Actual Date of Completion: AUG 2013
26
REFERENCES
Project Name:
San Antonio Ave Street & Storm Drain
Location: Various streets in Upland, CA
Owner:
City of Upland
Owner Contact (name and current phone number):
Bob Critchfield. P.E.
(909) 263 -5678 bcritchfield @ci.upland.ca.us
Architect or Engineer Contact (name and current phone number):
City of Upland
B ob Critchfield, P.E. (909) 263 -5678 bcritchfield @ci .upland.ca.us
Construction Manager (name and current phone number):
City of Upland
Bob Critchfield, P.E. ( 909) 263 -5678 bcr itchfield @ci.upland.ca.us
Description of Project, Scope of Work Performed:
6,505 LF of storm drains including large pipe (90" 84" 78" RCP )
working in major streets at 20' depths.
Total Value of Construction (including change orders):
Original Scheduled Completion Date: April 2008
Time Extensions Granted (number of days): 0
Actual Date of Completion: April 2008
$ 5,184,213
26
REFERENCES
Project Name: Sun Valley Tuxford Drain
Location: Various streets in Sun Valley, CA
Owner: Los Angeles County Dept. of Public Works
Owner Contact (name and current phone number):
Lo Angeles County Dept. of Public Works
Eric Updyke, P.E. (626) 458 -3122 eupdyke @dpw.lacounty.gov
Architect or Engineer Contact (name and current phone number):
Los Angeles County Dept. of Public Works
Eric Updyke, RE, (626) 458 -3122 eupdyke @dpw.lacounty.gov
Construction Manager (name and current phone number):
Eric Updyke, P.E.
(626) 458 -3122 eupdyke @dpw.lacounty.gov
Description of Project, Scope of Work Performed:
Storm Drain system with sediment detention pump station
Total Value of Construction (including change orders): $ 3,725 ,036.73
Original Scheduled Completion Date: Feb 2006
Time Extensions Granted (number of days): 1 month
Actual Date of Completion: March 2006
26
REFERENCES
Project Name:
5A Hollyhills Unit 7 & 5B Hollyhills Unit 8A
Location: Various streets in Beverly Hills and Westwood, CA
Owner: Los Angeles County Dept. of Public Works
Owner Contact (name and current phone number):
Lo Angeles County Dept. of Public Works
Eric Updyke, P.E. (626) 458 -3122 eup dyke @dpw.lacounty.gov
Architect or Engineer Contact (name and current phone number):
Los Angeles County Dept. of Public Works
Eric Updyke, P.E. ( 458 -3122 eupdyke @dpw.la county.gov
Construction Manager (name and current phone number):
Eric Uodvke. P.E.
(626) 458 -3122 eupdyke @dpw.lacounty.gov
Description of Project, Scope of Work Performed:
11, 861 LF of storm drains including large diameter box and pipe (108" RCP and RC Box 10' -7'wx 10' -4'h)
working in major streets (Santa Monica Blvd., Sunset Blvd) groundwater, solid sheeting, night work, 20' depths
settlement monitoring, noise control, resident relocations, highlines, bypassing and major traffic flow diversions
Total Value of Construction (including change orders): 7 $ 6,998,871 & 8A $ 6,8 78,505
Original Scheduled Completion Date:
Dec 2003
Time Extensions Granted (number of days): Value engineering extensions 8 mont
Actual Date of Completion: August 2004
26
REFERENCES
Project Name:
Location
Owner:
Joint Outfall H, Unit 5D, Relief Trunk Sewer
Various streets in South El Monte and County Regional Parkland
L.A. County Sanitation District
Owner Contact (name and current phone number):
Tommy Sung, P.E.
TSung @lacsd.org (562) 699 -7411
Architect or Engineer Contact (name and current phone number):
L.A. County Sanitation District
Tommy Sung, P.E. TSung @lacsd.org (562) 699 -7411
Construction Manager (name and current phone number):
Tommy Sung, P.E.
TSung @lacsd.org (562) 699 -7411
Description of Project, Scope of Work Performed:
3,200' LF of 48" to 18" VCP TRUNK SEWER depths 5' -21' including Jacking beneath 60 FWY
live flow diversions without bypassing, in major streets and parklands.
Total Value of Construction (including change orders): $ 8,601,341.50
Original Scheduled Completion Date: 12 months, Aug 2010
Time Extensions Granted (number of days): 9 month early completion
Actual Date of Completion: DEC 2009
26
SECTION 3
NON - COLLUSION AFFIDAVIT
CBF -13
BIDDER:�� �u
NON - COLLUSION AFFIDAVIT
In accordance with Public Contract Code Section 7106, the undersigned, being first duly
sworn, deposes and says that he or she holds the position listed below with the bidder, the
party making the foregoing bid, that the bid is not made in the interest of, or on behalf of, any
undisclosed person, partnership, company, association, organization, or corporation; that the
bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced
or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly
colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham
bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly
or indirectly, sought by agreement, communication, or conference with anyone to fix the bid
price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the
bid price, or of that of any other bidder, or to secure any advantage against the public body
awarding the contract of anyone interested in the proposed contract; that all statements
contained in the bid are true; and, further, that the bidder has not, directly or indirectly,
submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged
information or data relative thereto, or paid, and will not pay, any fee to any corporation,
partnership, company association, organization, bid depository, or to any member or agent
thereof to effectuate a collusive or sham bid.
ignature
Typed or Printed Name
Title
Bidd
Subscribed and sworn before me
This _ day of 20_
t (Seal)
Notary Public in and for
the State of California
My Commission Expires:
CBF -14
CALIFORNIA JURAT
A notary public or other officer completing this certificate verifies only the identity of the
individual who signed the document to which this certificate is attached, and not the
truthfullness, accuracy, or validity of that document.
State of California
ss-
County of Los Angeles
Subscribed and sworn to (or affirmed) before me,
on this 8 th I day of JULY , 2015
by Dave Screm, proved to me on the basis of
satisfactory evidence to be the person(s) who
appeared before me.
ANTON BRKIC [
Commission # 1980971
Notary Public - California z
z Los Angeles County
My Comm. Expires Jul 2, 2016
Anton Brkic, Notary Public (Notary seal)