The URL can be used to link to this page

2400 - Los Angeles County Metropolitant Transportation- 710 Mobility Funding Agreement - I-10/Rosemead Freeway - MR4.1.2.08FTIP #: LA9918871 MEASURE R FUNDING AGREEMENT HIGHWAY PROGRAM (General) Project#: MR4.1.2.08 FA# 9200000000MR41208 This Funding Agreement ("FA") is made and entered into effective as of April 7, 2020 ("Effective Date"), and is by and between the Los Angeles County Metropolitan Transportation Authority ("LACMTA") and City of Rosemead ("GRANTEE") for I-10/Rosemead Boulevard Freeway [Westbound] Ramp Improvements, LACMTA Project ID# MR4.1.2.08 and FTIP# LA9918871, (the "Project"). This Project is eligible for funding under Line 36 of the Measure R Expenditure Plan. WHEREAS, LACMTA adopted Ordinance #08-01, the Traffic Relief and Rail Expansion Ordinance, on July 24, 2008 (the "Ordinance"), which Ordinance was approved by the voters of Los Angeles County on November 4, 2008 as "Measure R" and became effective on January 2, 2009. WHEREAS, $780,000,000 in Measure R funds was identified in Line 36 of the Measure R Expenditure Plan for the SR -710 North Gap Closure [tunnel] Project [SR -710 North]. WHEREAS, the LACMTA Board at its May 25, 2017 meeting, reallocated the remaining Measure R Funds for the SR -710 North Project to new mobility improvement projects within the San Gabriel Valley subregion, if consistent with the purpose and need of the Gap Closure Project to relieve congestion on local streets along the SR -710 alignment between Interstates 10 and 210, with the highest priority for projects proximate to the Interstate 10 freeway. WHEREAS, the funding set forth herein is intended to fund the Project Approval/Environmental Document (PAED), Plans, Specifications and Estimates (PS&E), Right -of -Way, and Construction, of the Project. WHEREAS, the LACMTA Board, at its September 26, 2019 meeting, programmed $6,000,000, in Measure R Funds to GRANTEE for Project Approval/Environmental Document (PAED), Plans, Specifications and Estimates (PS&E), Right -of -Way, and Construction, subject to the terms and conditions contained in this FA; and WHEREAS, the Funds are currently programmed as follows: $300,000 in Measure R Funds in Fiscal Year FY 2020-21, $500,000 in FY 2021-22, $200,000 in FY 2022-23, $4,600,000 in FY 2023-24, and $400,000 in FY 2024-25. The total designated for Project Approval/Environmental Document (PAED), Plans, Specifications and Estimates (PS&E), Right -of -Way, and Construction of the Project is $6,000,000. NOW, THEREFORE, the parties hereby agree as follows: The terms and conditions of this FA consist of the following and each is incorporated by reference herein as if fully set forth herein: 1. Part I — Specific Terms of the FA 2. Part II — General Terms of the FA 3. Attachment A — Project Funding Rev: 02.20.2020 1 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 4. Attachment B — Measure R Expenditure Plan Guidelines 5. Attachment B-1— Expenditure Plan- Cost & Cash Flow Budget 6. Attachment C — Scope of Work 7. Attachment D — Project Reporting and Expenditure Guidelines 8. Attachment D-1— intentionally omitted 9. Attachment D-2 — Quarterly Progress/Expenditure Report 10. Attachment E — Federal Transportation Improvement Program (FTIP) Sheet 11. Attachment F — Bond Requirements 12. Attachment G — Special Grant Conditions 13. Any other attachments or documents referenced in the above documents In the event of a conflict, the Special Grant Conditions, if any, shall prevail over the Specific Terms of the FA and any attachments and the Specific Terms of the FA shall prevail over the General Terms of the FA. Rev: 02.20.2020 2 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 IN WITNESS WHEREOF, the parties have caused this FA to be executed by their duly authorized representatives as of the dates indicated below: LACMTA: LOS AN9.ES COUNTY METROPOLITAN TRANSPORTATION AUTHORITY By: A. Washington Executive Officer APPROVED AS TO FORM: MARY C. WICK14AM County Counsel By: Deputy GRANTEE: CITY OF ROSEMEAD Gloria Molleda City Manager APPROVED AS TO FORM: By: QV � Rachel H. Richman City Attorney Date: 0 Date: 4) 1-7 h o Date:�� Date: 1(42-1 Rev: 02.20.2020 3 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 PART SPECIFIC TERMS OF THE FA Project#: MR4.1.2.08 FA# 9200000000MR41208 1. Title of the Project (the "Project"): I-10/Rosemead Boulevard Freeway [Westbound] Ramp Improvements — Project Approval/Environmental Document (PAED), Plans, Specifications and Estimates (PS&E), Right -of -Way, and Construction. LACMTA Project ID# MR4.1.2.08, FTIP# LA9918871. Grant Funds: 2.1 Programmed Funds for this Project consist of the following: Measure R Funds. 2.2 To the extent the Measure R Funds are available; LACMTA shall make to GRANTEE a grant of the Measure R funds in the amount of $6,000,000 (the "Fund") for the Project. LACMTA Board of Directors' action of September 26, 2019 granted the Measure R Funds for the Project. The Funds are programmed over five years for Fiscal Years (FY) FY 2020-21, FY 2021-22, FY 2022-23, FY 2023-24, and FY 2024-25. 3. This grant shall be paid on a reimbursement basis. GRANTEE must provide the appropriate supporting documentation with the Quarterly Progress/Expenditure Report. GRANTEE Funding Commitment, if applicable, must be spent in the appropriate proportion to the Funds with each quarter's expenditures. LACMTA will withhold five percent (5%) of eligible expenditures per invoice as retention pending an audit of expenditures and completion of scope of work. 4. Attachment A the "Project Funding" documents all sources of funds programmed for the Project as approved by LACMTA. The Project Funding includes the total programmed funds for the Project, including the Funds programmed by LACMTA and, if any, the GRANTEE Funding Commitment of other sources of funding. The Project Funding also includes the fiscal years in which all the funds for the Project are programmed. The Funds are subject to adjustment by subsequent LACMTA Board Action. 5. Attachment B-1 is the Expenditure Plan- Cost & Cash Flow Budget (the "Expenditure Plan"). It is the entire proposed cash flow, the Budget and financial plan for the Project, which includes the total sources of all funds programmed to the Project, including GRANTEE and other entity funding commitments, if any, for this Project as well as the fiscal year and quarters the Project funds are anticipated to be expended. GRANTEE shall update the Expenditure Plan annually, no later than December 31, and such update shall be submitted to LACMTA's Senior Executive Officer of Construction & Engineering in writing. If the LACMTA's Senior Executive Officer of Construction & Engineering concurs with such updated Expenditure Plan in writing, Attachment B-1 shall be replaced with the new Attachment B-1 setting forth the latest approved Expenditure Plan. Payments under this FA shall be consistent with Attachment B-1 as revised from time to time. Any change to the final milestone date must be made by a fully executed amendment to this FA. 6. Attachment C is the "Scope of Work". The GRANTEE shall complete the Project as described in the Scope of Work This Scope of Work shall include a detailed description of the Rev: 02.20.2020 4 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 Project and the work to be completed, including anticipated Project milestones and a schedule consistent with the lapsing policy in Part II, Section 9, and a description of the Project limits, if applicable. No later than December 31 of each year, GRANTEE shall notify LACMTA if there are any changes to the final milestone date set forth in the schedule or any changes to the Scope of Work. If LACMTA agrees to such changes, the parties shall memorialize such changes in an amendment to this FA. Work shall be delivered in accordance with the schedule and scope identified in this FA unless otherwise agreed to by the parties in writing in an amendment to this F.A. If GRANTEE fails to meet milestones or delivery of the Project, LACMTA will have the option to suspend or terminate the FA for default as described in Part II, Sections 2, 9, 10 and 11 herein below. To the extent interim milestone dates are not met but GRANTEE believes and can show documentation acceptable to LACMTA supporting GRANTEE'S ability to make up the time so as to not impact the final milestone date, GRANTEE shall notify LACMTA of such changes in its Quarterly Progress/Expenditure Reports and such interim milestone dates will automatically be amended to the latest interim milestone dates provided in the Quarterly Progress/Expenditure Reports Attachment D-2. In no event can the final milestone date be amended by a Quarterly Progress/Expenditure Report, 7. No changes to this FA, including but not limited to the Funds, and any other source of funds from LACMTA in the Project Funding, Expenditure Plan or the Scope of Work shall be allowed without an amendment to the original FA, approved and signed by both parties. 8. Attachment D is the "Project Reporting & Expenditure Guidelines". GRANTEE shall complete the "Quarterly Progress/Expenditure Report". The Quarterly Progress/ Expenditure Report are attached to this FA as Attachment D_2 in accordance with Attachment D — Project Reporting and Expenditure Guidelines. 9. Attachment B, the "FTIP PROJECT SHEET (PDF)", is required to ensure that the Project is programmed correctly in the most up-to-date FTIP document. The FTIP PROJECT SHEET (PDF) can be found in ProgramMetro FTIP database under the reports section at hnp://program.metro.net. All projects that receive funding through Measure R must be programmed into the FTIP, which includes locally funded regionally significant projects for information and air quality modeling purposes. GRANTEE shall review the Project in ProgramMetro each year and update or correct the Project information as necessary during a scheduled FTIP amendment or adoption. GRANTEE will be notified of amendments and adoptions to the FTIP via e-mail. Changes to the FTIP through ProgramMetro should be made as soon as possible after GRANTEE is aware of any changes to the Project, but no later than October 1 of the year the change or update is effective. Should GRANTEE fail to meet this date, it may affect GRANTEE's ability to access funding, delay the Project and may ultimately result in the Funds being lapsed. 10. LACMTA anticipates it may need to avail itself of lower cost bonds or other debt, the interest on which is tax exempt for federal tax purposes and/or Build America Bonds as defined in the American Reinvestment and Recovery Act of 2009 or similar types of bonds (collectively, the 'Bonds") to provide at least a portion of its funding commitments under this Agreement to GRANTEE. GRANTEE shall ensure that the expenditure of the Funds disbursed to GRANTEE does not jeopardize the tax -exemption of the interest, the Federal subsidy payment or the tax credit, as applicable, as specified in the Bond Requirements Rev: 02.20.2020 5 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 attached as Attachment F to this Agreement, GRANTEE agrees to provide LACMTA with progress reports, expenditure documentation, and any other documentation as reasonably requested by LACMTA and necessary for LACMTA to fulfill its responsibilities as the grantee or administrator or bond issuer of the Funds. With regard to LACMTA debt financing to provide any portion of the Funds, GRANTEE shall take all reasonable actions as may be requested of it by LACMTA's Project Manager for the Project, to assist LACMTA in demonstrating and maintaining over time, compliance with the relevant sections of the Federal Tax Code to maintain such bonds tax status. 11. GRANTEE shall comply with the "Special Grant Conditions" attached as Attachment G, if any. 12. No changes to the (i) Grant amount, (ii) Project Funding, (iii) the Scope of Work (except as provided herein), (iv) Final milestone date or (v) Special Grant Conditions, shall be allowed without a written amendment to this FA, approved and signed by the LACMTA Chief Executive Officer or his/her designee and GRANTEE. Modifications that do not materially affect the terms of this FA, such as redistributing Funds among existing budget line items or non- material schedule changes must be formally requested by GRANTEE and approved by LACMTA in writing. Non -material changes are those changes which do not affect the grant amount or its schedule, Project Funding, or the Scope of Work, including the Work schedule. 13. LACMTA's Address: Los Angeles County Metropolitan Transportation Authority One Gateway Plaza Los Angeles, CA 90012 Attention: Julio Perucho LACMTA Project Manager Mail Stop 99-18-2 Phone (213) 922-4387 E-mail PeruchoJ@metro.net 14. GRANTEE's Address: City of Rosemead 8838 East Valley Boulevard Rosemead, CA 91770 Attention: Christopher Daste Phone: (626) 569-2158 Email: cdaste@cityofrosemead.org Rev: 02.20.2020 6 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 PART II GENERAL TERMS OF THE FA 1. TERM Project#: MR4.1.2.08 FA# 9200000000MR41208 The term of this FA shall commence on the Effective Date of this FA, and shall terminate upon the occurrence of all of the following, unless terminated earlier as provided herein: (i) the agreed upon Scope of Work has been completed; (ii) all LACMTA audit and reporting requirements have been satisfied; and (iii) the final disbursement of the Funds has been made to GRANTEE. All eligible Project expenses as defined in the Reporting and Expenditure Guidelines (Attachment D), incurred after the FA Effective Date shall be reimbursed in accordance with the terms and conditions of this FA unless otherwise agreed to by the parties in writing. 2. SUSPENSION ORTERMINATION Should LACMTA determine there are insufficient Measure R Funds available for the Project, LACMTA may suspend or terminate this FA by giving written notice to GRANTEE at least thirty (30) days in advance of the effective date of such suspension or termination. If a Project is suspended or terminated pursuant to this section, LACMTA will not reimburse GRANTEE any costs incurred after that suspension or termination date, except those costs necessary to: (i) to return any facilities modified by the Project construction to a safe and operable state; and (ii) suspend or terminate the construction contractor's control over the Project. LACMTA's share of these costs will be consistent with the established funding percentages outlined in this FA. 3. INVOICE BY GRANTEE Unless otherwise stated in this FA, the Quarterly Progress/ Expenditure Report, with supporting documentation of expenses, Project progress and other documents as required, which has been pre -approved by LACMTA, all as described in Part II, Section 6.1 of this FA, shall satisfy LACMTA invoicing requirements. Grantee shall only submit for payment the LACMTA pre -approved Quarterly Progress/ Expenditure Report Packets to the LACMTA Project Manager at the email address shown in Part I and to LACMTA Accounts Payable Department as shown below. Submit invoice with supporting documentation to: ACCOUNTSPAYABLIMMETRO.NET (preferable) or mail to: Los Angeles County Metropolitan Transportation Authority Accounts Payable P. O. Box 512296 Los Angeles, CA 90051-0296 All invoice material must contain the following information: Re: LACMTA Project ID# MR4.1.2.08 and FA# FA9200000000MR41208 [Julio Perucho; Mail Stop 99-18-2] Rev: 02.20.2020 7 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 4. USE OF FUNDS Project#: MR4.1.2.08 FA# 9200000000MR41208 4.1 GRANTEE shall utilize the Funds to complete the Project as described in the Scope of Work and in accordance with the Reporting and Expenditure Guidelines and the specifications for use for the transportation purposes described in the Ordinance. 4.2 Attachment C shall constitute the agreed upon Scope of Work between LACMTA and GRANTEE for the Project. The Funds, as granted under this FA, can only be used towards the completion of the Scope of Work detailed in Attachment C. 4.3 GRANTEE shall not use the Funds to substitute for any other funds or projects not specified in this FA. Further, GRANTEE shall not use the Funds for any expenses or activities above and beyond the approved Scope of Work (Attachment C) without an amendment to the FA approved and signed by the LACMTA Chief Executive Officer or his Designee. To the extent LACMTA provides GRANTEE with bond or commercial paper proceeds, such Funds may not be used to reimburse for any costs that jeopardize the tax exempt nature of such financings as reasonably determined by LACMTA and its bond counsel. 4.4 GRANTEE must use the Funds in the most cost-effective manner. If GRANTEE intends to use a consultant or contractor to implement all or part of the Project, LACMTA requires that such activities be procured in accordance with GRANTEE's contracting procedures and consistent with State law as appropriate. GRANTEE will also use the Funds in the most cost-effective manner when the Funds are used to pay "in-house" staff time. This effective use of funds provision will be verified by LACMTA through on- going Project monitoring and through any LACMTA interim and final audits. 4.5 GRANTEE'S employee, officers, councilmembers, board member, agents, or consultants (a "GRANTEE Party") are prohibited from participating in the selection, award, or administration of a third -party contract or sub -agreement supported by the Funds if a real or apparent conflict of interest would be involved. A conflict of interest would include, without limitation, an organizational conflict of interest or when any of the following parties has a financial or other interest in any entity selected for award: (a) a GRANTEE Party (b) any member of a GRANTEE Party's immediate family, (c) a partner of a GRANTEE Party; (d) any organization that employs or intends to employ any of the above. This conflict of interest provision will be verified by LACMTA through on-going Project monitoring and through any LACMTA interim and final audits. 4.6 If a facility, equipment (such as computer hardware or software), vehicle or property, purchased or leased using the Funds, ceases to be used for the proper use as originally stated in the Scope of Work, or the Project is discontinued, any Funds expended for that purpose must be returned to LACMTA as follows: GRANTEE shall be required to repay the Funds in proportion to the useful life remaining and in an equal proportion of the grant to GRANTEE Funding Commitment ratio. 4.7 If the Project requires the implementation of an Intelligent Transportation Systems ("ITS") project, GRANTEE shall ensure the Project is consistent with the Regional ITS Architecture. Attachment H, the Los Angeles County Regional ITS Rev: 02.20.2020 8 Measure R Funding Agreement— Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 Architecture (CONNECT -IT) Consistency Self -Certification Form, must be completed and signed for planned ITS projects and/or ITS projects that use local, state, or federal funds programmed or administered through LACMTA. Refer to www.laconnect-it.com to find information about the CONNECT -IT Service Packages. 4.8 If any parking facilities are designed and/or constructed using the Funds, GRANTEE shall coordinate with LACMTA parking program staff (see www.metro.net for staff listing) in the planning, design and management of the facility and shall ensure that its implementation is consistent with the LACMTA adopted parking policy. For the parking policy, see http://media.metro.net/projects_studies/call projects/images./09%20Appendix%20D%20Pa rking%20Policy.pdf S. REIMBURSEMENT OF FUNDS Funds will be released on a reimbursement basis in accordance with invoices submitted in support of the Quarterly Progress/Expenditure Reports. LACMTA will make all disbursements electronically unless an exception is requested in writing. Reimbursements via Automated Clearing House (ACH) will be made at no cost to GRANTEE. GRANTEE must complete the ACH form and submit such form to LACMTA before grant payments can be made. ACH Request Forms can be found at www.metro,net/projects/cal projects/call_projects-reference- documents/. GRANTEE must provide detailed supporting documentation with its Quarterly Progress/Expenditure Reports. GRANTEE Funding Commitment, if any, must be spent in direct proportion to the Funds with each quarter's payment. G. REPORTING AND AUDIT REQUIREMENTS/PAYMENT ADJUSTMENTS 6.1 GRANTEE shall submit the draft of Quarterly Progress/Expenditure Report (Attachment D-2), within sixty (G0) days after the close of each quarter on the last day of the months November, February, May and August to the LACMTA Project Manager for review and pre -approval of the applicable report. LACMTA Project Manager shall review and respond in writing to the draft Quarterly Progress/Expenditure Reports within thirty (30) calendar days from receipt. Grantee shall submit the LACMTA pre -approved Quarterly Progress/Expenditure Report no later than five (5) days after receipt of LACMTA's written approval. Should GRANTEE fail to submit either the draft or pre -approved reports within five (5) days of the due date and/or submit incomplete reports, LACMTA will not reimburse GRANTEE until the completed required reports are received, reviewed, and approved. The Quarterly Progress/Expenditure Reports shall include all appropriate documentation (such as contractor invoices, timesheets, receipts, etc.), and any changes to interim milestone dates that do not impact the final milestone date. All supporting documents must include a clear justification and explanation of their relevance to the Project. If no activity has occurred during a particular quarter, GRANTEE will still be required to submit the Quarterly Progress/Expenditure Reports indicating no dollars were expended that quarter. If a request for reimbursement exceeds $500,000 in a single month, then GRANTEE can submit such an invoice once per month with supporting documentation. Expenses that are not invoiced to LACMTA Accounts Payable Rev: 02.20.2020 9 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 within ninety (90) days after the lapsing date specified in Part II, Section 9.1 below are not eligible for reimbursement. 6.2 GRANTEE shall submit the Project expenditure estimates for the subsequent fiscal year by February of each year. LACMTA will use the estimates to determine the Project budget for the upcoming fiscal year. 6.3 LACMTA, and/or its designee, shall have the right to conduct audits of the Project as deemed appropriate, such as financial and compliance audits, interim audits, pre- award audits, performance audits and final audits. LACMTA will commence a final audit within six months of receipt of acceptable final invoice, provided the Project is ready for final audit (meaning all costs and charges have been paid by GRANTEE and invoiced to LACMTA, and such costs, charges and invoices are properly documented and summarized in the accounting records to enable an audit without further explanation or summarization including actual indirect rates for the period covered by the FA period under review). GRANTEE agrees to establish and maintain proper accounting procedures and cash management records and documents in accordance with Generally Accepted Accounting Principles (GAAP). GRANTEE shall reimburse LACMTA for any expenditure not in compliance will the Scope of Work and/or not in compliance with other teens and conditions of this F.A. The allowability of costs for GRANTEE's own expenditures submitted to LACMTA for this Project shall be in compliance with Office of Management and Budget (OMB) Circular A-87. The allowability of costs for GRANTEE's contractors, consultants and suppliers expenditures submitted to LACMTA through GRANTEE's Quarterly Progress/Expenditures shall be in compliance with OMB Circular A-87 or Federal Acquisition Regulation (FAR) Subpart 31 and 2 CFR Subtitle A, Chapter II, Part 225 (whichever is applicable). Findings of the LACMTA audit are final. When LACMTA audit findings require GRANTEE to return monies to LACMTA, GRANTEE agrees to return the monies within thirty (30) days after the final audit is sent to GRANTEE. 6.4 GRANTEE's records shall include, without limitation, accounting records, written policies and procedures, contract files, original estimates, correspondence, change order files (including documentation covering negotiated settlements), invoices, and any other supporting evidence deemed necessary by LACMTA to substantiate charges related to the Project (all collectively referred to as "records"). Such records shall be open to inspection and subject to audit and reproduction by LACMTA auditors or authorized representatives to the extent deemed necessary by LACMTA to adequately permit evaluation of expended costs. Such records subject to audit shall also include, without limitation, those records deemed necessary by LACMTA to evaluate and verify, direct and indirect costs, (including overhead allocations) as they may apply to costs associated with the Project. These records must be retained by GRANTEE for three years following final payment under this Agreement. Payment of retention amounts shall not occur until after the LACMTA's final audit is completed. 6.5 GRANTEE shall cause all contractors to comply with the requirements of Part II, Section 5, paragraphs 6.2 and 6.3 above. GRANTEE shall cause all contractors to cooperate fully in furnishing or in making available to LACMTA all records deemed necessary by LACMTA auditors or authorized representatives related to the Project. Rev: 02.20.2020 10 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 6.6 LACMTA or any of its duly authorized representatives, upon reasonable written notice, shall be afforded access to all GRANTEE'S records and its contractors related to the Project, and shall be allowed to interview any employee of GRANTEE and its contractors through final payment to the extent reasonably practicable. 6.7 LACMTA or any of its duly authorized representatives, upon reasonable written notice, shall have access to the offices of GRANTEE and its contractors, shall have access to all necessary records, including reproduction, at no charge to LACMTA, and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the terms and conditions of this FA. 6.8 When business travel associated with the Project requires use of a vehicle, the mileage incurred shall be reimbursed at the mileage rates set by the Internal Revenue Sei vice, as indicated in the United States General Sei vices Administration Federal Travel Regulation, Privately Owned Vehicle Reimbursement Rates. 6.9 GRANTEE shall be responsible for ensuring all contractors/ subcontractors for the Project comply with the terms of the Ordinance. GRANTEE shall cooperate with LACMTA Management Audit Sei vices Department such that LACMTA can meet its obligations under the Ordinance. 6.10 GRANTEE shall certify each invoice by reviewing all subcontractor costs and maintaining internal control to ensure that all expenditures are allocable, allowable and reasonable and in accordance with OMB A-87 or FAR subpart 31 and 2 CFR Subtitle A, Chapter II, part 225, (whichever is applicable) and the terms and conditions of this FA. 6.11 GRANTEE shall also certify final costs of the Project to ensure all costs are in compliance with OMB A-87 or FAR subpart 31 and 2 CFR Subtitle A, Chapter II, part 225, (whichever is applicable) and the terms and conditions of this FA. 6.12 In addition to LACMTA's other remedies as provided in this FA, LACMTA may withhold the Funds if the LACMTA audit has determined that GRANTEE failed to comply with the Scope of Work (such as misusing Funds or failure to return Funds owed to LACMTA in accordance with LACMTA audit findings) and /or is severely out of compliance with other terms and conditions as defined by this FA, including the access to records provisions of Part II, Section 6. 7. GRANT This is a one-time only grant of the Measure R Funds subject to the terms and conditions agreed to herein. This grant does not imply nor obligate any future funding commitment on the part of LACMTA. Rev: 02.20.2020 11 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 8. SOURCES AND DISPOSITION OF FUNDS 8.1 The obligation for LACMTA to grant the Funds for the Project is subject to sufficient Funds being made available for the Project by the LACMTA Board of Directors. If such Funds are not made available as anticipated from Measure R Program revenues, LACMTA will have the right to adjust the cash flow accordingly until such funds become available. LACMTA shall have no obligation to provide any other funds for the Project, unless otherwise agreed to in writing by LACMTA. 8.2 GRANTEE shall fully fund and contribute the GRANTEE Funding Commitment, if any is identified in the Project Funding (Attachment A), towards the cost of the Project. If the Funds identified in Attachment A are insufficient to complete the Project, GRANTEE agrees to secure and provide such additional non-LACMTA programmed funds necessary to complete the Project. 8.3 GRANTEE shall be responsible for any and all cost"overruns for the Project pursuant to Section 8.2. 8.4 GRANTEE shall be eligible for the Funds up to the grant amount specified in Part I, Section 2 of this FA subject to the terms and conditions contained herein. Any Funds expended by GRANTEE prior to the Effective Date of this FA shall not be reimbursed nor shall they be credited toward the GRANTEE Funding Commitment requirement, without the prior written consent of LACMTA. GRANTEE Funding Commitment dollars expended prior to the year the Funds are awarded shall be spent at GRANTEE's own risk, or as delineated in a Letter of No Prejudice executed by the prospective GRANTEE and LACMTA. 8.5 If GRANTEE receives outside funding for the Project in addition to the Funds identified in the Project Funding and the Expenditure Plan at the time this grant was awarded, this FA shall be amended to reflect such additional funding. If, at the time of final invoice or voucher, funding for the Project (including the Funds, GRANTEE Funding Commitment, and any additional funding) exceeds the actual Project costs, then the cost savings shall be applied in the same proportion as the sources of funds from each party to this FA as specified in the Project Funding and both the Funds and GRANTEE Funding Commitment required for the Project shall be reduced accordingly. LACMTA shall have the right to use any cost savings associated with the Funds at its sole discretion, including, without limitation, programming the unused Funds to another project or to another grantee. If, at the time of final voucher, it is determined that GRANTEE has received Funds in excess of what GRANTEE should have received for the Project, GRANTEE shall return such overage to LACMTA within 30 days from final voucher. 9. TIMELY USE OF FUNDS/ REPROGRAMMING OF FUNDS 9.1 GRANTEE must demonstrate timely use ofthe Funds by: (i) Executing this FA within ninety (90) days of receiving formal transmittal of the FA from LACMTA, or by December 31 of the Rev: 02.20.2020 12 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 first Fiscal Year in which the Funds are programmed, whichever date is later; and (ii) Beginning Project Design, Preliminary Engineering (PE) within six (6) months from completion of environmental clearance, if appropriate. (iii) Expending Project Development or Right -of -Way costs (including by deposit into a condemnation action) by the end of the second (2ud) fiscal year following the year the Funds were first programmed; and (iv) Executing Contracts for Construction or Capital purchase within twelve (12) months from the date of completion of design; and (v) Delivering Work in accordance with schedule; changes to the schedule will require an Amendment to Attachment C to reflect updated milestone dates. Meeting the Project milestone due dates as agreed upon by the LACMTA and GRANTEE in Attachment C (Scope of Work) of this FA; and (vi) Submitting the Quarterly Progress/Expenditure Reports as described in Part II, Section 6.1 of this FA; and (vii) Expending the Funds granted under this FA for allowable costs within three years or 36 months July 1 of the Fiscal Year in which the Funds are programmed, unless otherwise stated in this FA. All Funds programmed for FY 2020-21 are subject to lapse by June 30, 2023. All Funds programmed for FY 2021-22 are subject to lapse by June 30, 2024. All Funds programmed for FY 2022-23 are subject to lapse by June 30, 2025. All Funds programmed for FY 2023-24 are subject to lapse by June 30, 2026. All Funds programmed for FY 2024-25 are subject to lapse by June 30, 2027. 9.2 In the event that the timely use of the Funds is not demonstrated as described in Part II, Section 9.1 of this FA, the Project will be reevaluated by LACMTA and the Funds may be reprogrammed to another project by the LACMTA Board of Directors in accordance with the Ordinance. In the event that all the Funds are reprogrammed, this FA shall automatically terminate. 10. DEFAULT A Default under this FA is defined as any one or more of the following: (i) GRANTEE fails to comply with the terms and conditions contained herein; and/or (ii) GRANTEE fails to perform satisfactorily or make material changes, as determined by LACMTA at its sole discretion, to the Expenditure Plan, the Scope of Work, or the Project Funding without LACMTA's prior written consent or approval as provided herein. 11. REMEDIES 11.1 In the event of a Default by GRANTEE, LACMTA shall provide written notice of such Default to GRANTEE with a 30 -day period to cure the Default. In the event GRANTEE fails to cure the Default, or commit to cure the Default and commence the same Rev: 02.20.2020 13 Measure R Funding Agreement— Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 within such 30 -day period to the satisfaction of LACMTA, LACMTA shall have the following remedies: (i) LACMTA may terminate this FA; (ii) LACMTA may make no further disbursements of Funds to GRANTEE; and/or (iii) LACMTA may recover from GRANTEE any Funds disbursed to GRANTEE as allowed by law or in equity. 11.2 Effective upon receipt of written notice of termination from LACMTA, GRANTEE shall not undertake any new work or obligation with respect to this FA unless so directed by LACMTA in writing. Any Funds expended after termination shall be the sole responsibility of GRANTEE. 11.3 The remedies described herein are non-exclusive. LACMTA shall have the right to enforce any and all rights and remedies herein or which may be now or hereafter available at law or in equity. 12. COMMUNICATIONS 12.1 GRANTEE shall ensure that all Communication Materials contain recognition of LACMTA's contribution to the Project as more particularly set forth in "Funding Recipient Communications Guidelines" available online at http_//metro.net/partners-civic. The Funding Recipient Communications Guidelines may be changed from time to time during the course of this Agreement. GRANTEE shall be responsible for complying with the latest Funding Recipient Communications Guidelines during the term of this Agreement, unless otherwise specifically authorized in writing by the LACMTA Chief Communications Officer. 12.2 For purposes of this Agreement, "Communications Materials" include, but are not limited to, press events, public and external newsletters, printed materials, advertising, websites radio and public service announcements, electronic media, and construction site signage. A more detailed definition of "Communications Materials" is found in the Funding Recipient Communications Guidelines. 12.3 The Metro logo is a trademarked item that shall be reproduced and displayed in accordance with specific graphic guidelines. The preferred logo lock-up for Funding Recipients to use is included in the Funding Recipient Communications Guidelines. 12.4 GRANTEE shall ensure that any subcontractor, including, but not limited to, public relations, public affairs, and/or marketing firms hired to produce Project Communications Materials for public and external purposes will comply with the requirements contained in this Section. 12.5 The LACMTA Project Manager shall be responsible for monitoring GRANTEE's compliance with the terms and conditions of this Section. GRANTEE's failure to comply with the terms of this Section shall be deemed a default hereunder and LACMTA shall have all rights and remedies set forth herein. 13. OTHER TERMS AND CONDITIONS Rev: 02.20.2020 14 Measure R Funding Agreement— Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 13.1 This FA, along with its Attachments, constitutes the entire understanding between the parties, with respect to the subject matter herein. The FA shall not be amended, nor any provisions or breach hereof waived, except in writing signed by the parties who agreed to the original FA or the same level of authority. Adoption of revisions or supplements to the Guidelines shall cause such revisions or supplements to become incorporated automatically into this Agreement as though fully set forth herein. 13.2 GRANTEE is obligated to continue using the Project dedicated to the public transportation purposes for which the Project was initially approved. The Project right- of-way, the Project facilities constructed or reconstructed on the Project site, and/or Project property purchased, excluding construction easements and excess property (whose proportionate proceeds shall be distributed in an equal proportion of the grant to GRANTEE Funding Commitment ratio), shall remain dedicated to public transportation use in the same proportion and scope and to the same extent as described in this FA. Equipment acquired as part of the Project, including office equipment, vehicles, shall be dedicated to that use for their full economic life cycle, including any extensions of that life cycle achieved by reconstruction, rehabilitation, or enhancements. 13.3 In the event that there is any legal court (e.g., Superior Court of the State of California, County of Los Angeles, or the U.S. District Court for the Central District of California) proceeding between the parties to enforce or interpret this FA, to protect or establish any rights or remedies hereunder, the prevailing palty shall be entitled to its costs and expenses, including reasonable attorney's fees. 13.4 Neither LACMTA nor any officer or employee thereof shall be responsible for any damage or liability occurring by reason of anything done or committed to be done by GRANTEE under or in connection with any work performed by and or service provided by GRANTEE, its officers, agents, employees, contractors and subcontractors under this FA. GRANTEE shall fully indemnify, defend and hold LACMTA and its subsidiaries, and its officers, agents and employees harmless from and against any liability and expenses, including without limitation, defense costs, any costs or liability on account of bodily injury, death or personal injury of any person or for damage to or loss of risk of property, any environmental obligation, any legal fees and any claims for damages of any nature whatsoever arising out of the Project, including without limitation: (i) use of the Funds by GRANTEE, or its officers, agents, employees, contractors or subcontractors; (ii) breach of GRANTEE's obligations under this FA; or (iii) any act or omission of GRANTEE, or its officers, agents, employees, contractors or subcontractors in the performance of the work or the provision of the services, in connection with the Project including, without limitation, the Scope of Work, described in this FA. 13.5 Neither party hereto shall be considered in default in the performance of its obligation hereunder to the extent that the performance of any such obligation is prevented or delayed by unforeseen causes including acts of God, acts of a public enemy, and government acts beyond the control and without fault or negligence of the affected party. Each party hereto shall give notice promptly to the other of the nature and extent of any such circumstances claimed to delay, hinder, or prevent performance of any obligations under this FA. Rev: 02.20.2020 15 Measure R Funding Agreement — Highways — General FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 13.6 GRANTEE shall comply with and ensure that work performed under this FA is done in compliance with Generally Accepted Accounting Principles (GAAP), all applicable provisions of federal, state, and local laws, statutes, ordinances, rules, regulations, and procedural requirements including Federal Acquisition Regulations (FAR), and the applicable requirements and regulations of LACMTA. GRANTEE acknowledges responsibility for obtaining copies of and complying with the terms of the most recent federal, state, or local laws and regulations, and LACMTA requirements including any amendments thereto. 13.7 GRANTEE agrees that the applicable requirements of this FA shall be included in every contract entered into by GRANTEE or its contractors relating to work performed under this FA and LACMTA shall have the right to review and audit such contracts. 13.8 GRANTEE shall not assign this FA, or any part thereof, without prior approval of the LACMTA Chief Executive Officer or his designee. Any assignment by GRANTEE without said prior consent by LACMTA shall be void and unenforceable. 13.9 This FA shall be governed by California law. If any provision of this FA is held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remaining provisions shall nevertheless continue in full force without being impaired or invalidated in any way. 13.10 The covenants and agreements of this FA shall inure to the benefit of, and shall be binding upon, each of the parties and their respective successors and assigns. 13.11 GRANTEE will advise LACMTA prior to any key Project staffing changes. Notice will be given to the parties at the address specified in Part I, unless otherwise notified in writing of change of address. 13.12 GRANTEE, in the performance of the work described in this FA, is not a contractor nor an agent or employee of LACMTA. GRANTEE attests to no organizational or personal conflicts of interest and agrees to notify LACMTA immediately in the event that a conflict, or the appearance thereof, arises. GRANTEE shall not represent itself as an agent or employee of LACMTA and shall have no powers to bind LACMTA in contract or otherwise. Rev: 02.20.2020 16 Measure R Funding Agreement — Highways — General FTIP 0: IA9918871 ATTACHMENT A - PROJECT FUNDING Measure R Program - Funding Agreement Projects - FA# 9200000000MR41208 Project Title: I-10/Rosemead Boulevard Freeway [Westbound] Ramp Improvements Project#: MR4.1.2.08 PROGRAMMED BUDGET- SOURCES OF FUNDS SOURCES OF FUNDS PdorYears FY20.21 FY21.22 FY22.23 FY23.24 PY24.25 Total %of Bu get Budget LACMTA PROGRAMMED FUNDING MBASURBRFUNDS 8 300,000 S 500,000 $ 200,000S 4,600,000 $ 400,000S 6,000,000 LACMTA PROGRAMMED FUNDS B YEARSUBTOTA $ $ 300,000 $ 500,000 $ 200,000 $ 4,600,000 $ 400,000 4 6,000,000 100% OTHER SOURCES OF FUNDING: LOCAL: 0% STATE: $ 0% FEDERAL: PRIVATE OR OTHER: $ 0% $ 0% OTHER FUNDINGSUBTOT $ _ $ $ _ $ -is $ _ S 0% TOTAL PROJECT FUNDS $ ).0001 $ 500,000 $ 200,000 1 $ 4,600,000 1 S 4 0,00011$ 6,OOD,000 I 100% Rev. 05.03.19 FA Measure R Htvys Gen Attachment A Project Fwids FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 ATTACHMENT B MEASURE R EXPENDITURE PLAN GUIDELINES PROJECT DEVELOPMENT AND RIGHT OF WAY State Law Requires All Measure R Project and Program Sponsors to Submit an Expenditure Plan To be eligible to receive Measure R revenues, an agency sponsoring a capital project or program must by state law (AB 2321) submit an expenditure plan that is acceptable to the Los Angeles County Metropolitan Transportation Authority (LACMTA). Pursuant to this law, LACMTA cannot release Measure R funds to capital project or program sponsors until an expenditure plan containing the following elements is submitted, reviewed and deemed satisfactory by LACMTA. LACMTA staff will request that an expenditure plan be submitted before malting a recommendation to the LACMTA Board to program funds to that project: o The estimated total cost for each project and program and/or each project or program activity; o Funds other than Measure R that the project or program sponsor anticipates will be expended on the projects and programs and/or each project or program activity; o The schedule during which the project sponsor anticipates funds will be available for each project and program and/or each project or program activity; and, o The expected completion dates for each project and program and/or project or program activity. Each of the above elements must be provided in enough detail to determine consistency with Measure R, the Long Range Transportation Plan for Los Angeles County, and the Los Angeles County Transportation Improvement Program (also a statutorily mandated function), as follows: o Project or program scope of work, including sufficient information to determine funding eligibility, including, but not limited to, the anticipated proportional use of current rail rights-of-way, state highways, and below -ground subways versus any other rights-of-way or above -ground work; o A current -year cost estimate breakdown of the major sub -elements of the project such as overhead, environmental and permit work, design and engineering, right-of-way, construction/installation (including maintenance facilities, rail yard, equipment and other major components), construction/installation support, interest costs, rolling stock, and other supporting components; o Any extraordinary project cost escalation issues, such as extraordinary commodity, right- of-way, surety, energy costs, etc.; o A specific and accurate description of the source, commitment, and anticipated annual availability of any federal, state, local, or private funding identified for the project if applicable including a 3% local funding contribution to rail projects if indicated in Measure R and necessary to meet project expenses, and if the source funds are in current or year -of -expenditure dollars; Rev: 11-1-14 1 FA Measure R Hwys Sub Attachment B Measure R Expenditure Guidelines FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 o An annual schedule, in current dollars, of anticipated costs by the cost estimate categories described above; and; o The expected completion by month and year of project or program completion. Below is an excerpt of AB 2321 (2008, Feuer), the state legislation that requires the expenditure plan. What AB 2321 (2008. Feuer) Says About the Expenditure Plan: Section b (3) B (f) Prior to submitting the ordinance to the voters, the MTA shall adopt an expenditure plan for the net revenues derived from the tax. The expenditure plan shall include, in addition to other projects and programs identified by the MTA, the specified projects and programs listed in paragraph (3) ofsubdivision (h), the estimated total cost for each project and program, funds other than the tax revenues that the MTA anticipates will he expended on the projects and programs, and the schedule during which the MTA anticipates funds will he available for each project and program. The MTA shall also identify in its expenditure plan the expected completion dates for each project described in subparagraph (A) of paragraph (3) ofsubdivision (h). To be eligible to receive zevenues derived f om the tax, an agency sponsoring a capital project or capital program shall submit to to MTA an expenditure plan for its project or program containing the same elements as the expenditure plan that MTA is required by this subdivision to prepare. (k) No later than 365 days prior to the adoption ofan amendment described in paragraph (1) to an expenditure plan adopted pursuant to subdivision (i, including, butnotlimited to, the expenditure plan adopted by the MTA board as 'AttachmerrtA "in Ordinance #08-01 adopted by the hoard on July 24, 2008, and in addition to any other notice requirements in the proposing ordinance, the board shall notify the Mernheis of the Legislature representing the County ofLos Angeles ofall of the following.• (1) A description ofthe proposed amendments to the adopted expenditure plan that would do any ofthe following. (A) Affect the amount ofnetrevenues derived from the taximposed pursuant to this act that is proposed to he expended on a capital project or projects identified in the adopted expenditure plan. (B) Affect the schedule for the availshility offunds proposed to be expended on a capital project or projects identified in the adopted expenditure plan, (C) Affect the schedule for the estimated or expected completion date ofa capital project or projects identified in the adopted expenditure plan. (2) The reason fol- the proposed amendment (3) The estimated impact the proposed amendment will have on the schedule, cost, scope, or timely availability offunding for the capital project or projects contained in the adopted expenditure plan. Rev: 11-1-14 2 FA Measure R Hwys Sub Attachment B Measure R Expenditure Guidelines ATTACHMENT B-1- EXPENDITURE PLAN COST & CASH FLOW BUDGET Measure R Program - Funding Agreement Projects - FA# 9200000000MR41208 Project Title: I-10/Rosemead Boulevard Freeway [Westbound] Ranlp Improvements Project#: MR4.1.2,08 PROGRAMMED SOURCES OF FUNDS SOURCES OF FUNDS FY 2020.21 1 Qtr 1 FY 2020.21 0tr2 FY 2020.21 1 Qtri FY2020.21 I Qtr4 FY 2021.22 Oftl FY 2021.22 tr2 FY 2021.22 Qtri FY 2021.22 1 Qtr4 TOTAL BUDGET LACMTA PROGRAMMED FUNDS: MEASURE R FUNDS: PAED $500 $1,500 $3,000 $25,000 $35,000 $35,000 550,000 $150,000 PS&E $7,500 $12,500 $15,000 $235,000 $120,000 $60,000 $100,000 $100,000 $650,000 RW Support $0 Const. Support $0 RW $o Construcdon $0 Tota MEASURE R $8,000 $14,000 $18,000 $260,000 $155,000 $95,000 $150,000 $100,000 $800,000 SUM PROG LACMTA FUNDS: $8,000 $14,000 $18,000 $260,000 $155,000 $95,000 $150,000 $100,000 $800,000 SOURCES OF FUNDS FY 2022.23 1 FY 2022.23 FY 2022.23 1 PY 2022.23 FY 2023.24 FY 2023.24 I FY 202324 I FY 202324 I TOTAL Qtr I Qtr2 Qtr3 1 Qtr4 1 qtrl tr2 Qtri Qbr4 BUDGET LACMTA PROGRAMMED FUNDS: MEASURE R FUNDS: PAED $0 PS&E $25,000 $25,000 $50,000 R\V Support $o FTIP #: LA9918871 ATTACHMENT C SCOPE OF WORK PROJECT TITLE: I-10/Rosemead Boulevard Freeway [Westbound] Ramp Improvements. Project#: MR4.1.2.08 FA# 9200000000MR41208 PROJECT LOCATION: The project is located in the City of Rosemead at the intersection of Rosemead Boulevard (State Route [SR] -164), Glendon Way, and Interstate 10 (I-10) Freeway Westbound (WB) On and Off Ramps at Rosemead Boulevard. PROJECT LIMITS: This project limits are the following: the intersection of Rosemead Boulevard (SR -164) and Glendon Way (approximate postmile: Route 164, LA 5.7) and I-10 Freeway WB On and Off Ramps at Rosemead Boulevard (approximate postmile: Route 10, LA 26.8), and extend approximately 500' north, east, south and west of the intersection to accommodate geometric/lane adjustments as necessary. NEXUS TO HIGHWAY OPERATION, DEFINITION/PROJECT PURPOSE: The proposed project involves improvements to Rosemead Boulevard (SR -164) and Glendon Way (approximate postmile: Route 164, LA 5.7) and I-10 Freeway WB On and Off Ramps at Rosemead Boulevard (approximate postmile: Route 10, LA 26.8). The improvements include geometric realignment and additional lanes to increase capacity, improve traffic flow, and reduce congestion at the intersection, which will continue to worsen over time without improvernents. PROJECT BACKGROUND: The proposed project was identified, and was awarded LACMTA Measure R fielding, as part of a broader package of projects known as the SR -710 Mobility Improvement Projects (MIPS). The SR - 710 MIPS are the result of reallocated Measure R Funds for the SR -710 North Project to new mobility improvement projects within the San Gabriel Valley subregion. These projects are consistent with the purpose and need of the Gap Closure Project to relieve congestion on local streets along the SR - 710 alignment between Interstates 10 and 210, with the highest priority for projects proximate to the Interstate 10 freeway. Rosemead Boulevard is one of the busiest regional corridors that extends from SR -60 to I-10 and from I-10 to the I-210 Freeways. Due to insufficient geometric configuration and lane capacities at the Rosemead Boulevard and I-10 Freeway WB On and Off Ramps, significant delays are experienced throughout the day. PROJECT BUDGET: COMPONENT PA/ED PS&E R/W Support R/W Capital Construction Support Construction Capital Total Budget Rev: 05.03.19 AMOUNT 150,000 700,000 0 0 750,000 4,400,000 $6,000,000 FA Measure R Hwys Gen Attachment C Scope of Work FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 SCOPE: The City plans to improve Rosemead Boulevard (SR -164) and Glendon Way and I-10 Freeway WB On and Off Ramps at Rosemead Boulevard and prepare PA/ED, PS&E, R/W, and Construction phase documents. The proposed irnprovements are as follows: 1. Widen east side of Rosemead Boulevard to add an exclusive right turn lane from NB Rosemead Boulevard to WB I-10 Freeway easterly On Ramp. 2. Add an additional lane for the I-10 Freeway easterly WB Off Ramp. 3. Add an exclusive right turn lane from WB Glendon Way to NB Rosemead Boulevard. 4. Eliminate left turn lane from I-10 Freeway westerly WB Off -Ramp to WB Glendon Way. 5. If determined to be feasible after further engineering analysis, widen west side of Rosemead Boulevard to provide a wider right turn lane (current right turn lane is approx. 10' wide, which is narrow). Widening this right turn lane by 1' or 2' (which will require narrowing the sidewalk, accordingly) would improve the traffic flow. 6. Reconfigure geometric alignment of west approach on Glendon Way west of Rosernead Boulevard and provide a left turn lane for from WB Glendon Way to WB I-10 Freeway westerly On Ramp. 7. Widen south-west corner of Glendon Way and I-10 WB westerly On-ramp to provide proper right turn lane and curb return to accommodate right turn traffic onto the ramps. DESIGN: I. Preliminary Design Tasks to be performed include, but are not limited to, the following: A. Conduct field visits of the project area to identify design issues. Record existing site conditions in photographs and/or video. B. Conduct survey of the project area, establishing horizontal and vertical control for the project as necessary. C. Identify and coordinate with all utilities in the project area to facilitate the final design of the Project. D. Verify if a geotechnical survey will be necessary. If yes, conduct geotechnical investigations as necessary. E. Verify if right-of-way (R/W) acquisitions and/or vacations will be necessary. At this point all work assumed to be within existing City and Caltrans R/W. F. Coordinate with Caltrans for work within Caltrans R/W and establish required environmental, review, approval and permitting process. G. Prepare construction cost estimate. II. Environmental Analysis It is anticipated this project will be either an exempt project or a Mitigated Negative Declaration (MND). Tasks to be performed include, but are not limited to, the following: A. Prepare Initial Study (IS), consistent with CEQA Guidelines. B. If IS results in any impacts, prepare MND or any other applicable environmental document as necessary. Rev: 05.03.19 2 FA Measure R Hwys Gen Attachment C Scope of Work FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 C. Prepare the Draft IS and Draft MND for public circulation as necessary, respond to questions and comments, and finalize the enviromnental process. D. Coordinate with Caltrans for work within Caltrans R/W for required environmental review and approval. III. Final Design Tasks to be performed include, but are not limited to, the following: A. Prepare plans for the required improvements, consistent with City and/or Caltrans format. B. Assist the City for any Community Information Workshop if necessary. C, Prepare construction specifications. D. Prepare an engineer's construction cost estimate based on the itemized quantity take -off from the contract documents. I?. Coordinate with Caltrans for work within Caltrans R/W and obtain required approval and permits. F. Complete Final Plans, Specifications and Estimates (PS&E) Bid Package. IV. Project Management Grantee expects to provide overall project and program management, fiulding management through its in-house staff, and by using its in-house, already approved, engineering consultant. RIGHT-OF-WAY: At this point, all work assumed to be within existing City and Caltrans R/W. CONSTRUCTION: The construction contract will be bid out per Public Contract Code and City requirements. Grantee expects to provide construction management, inspection, contract administration, funding management through its in-house staff, and by using its in-house, already approved, engineering consultant. Rev: 05.03.19 3 FA Measure R Hwys Gen Attachment C Scope of Work FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 MILESTONES: The implementation schedule for this project will be as follows: Rev: 05.03.19 4 FA Measure R Hwys Gen Attachment C Scope of Work START DATE COMPLETION DATE SOLICITATION BID PROPOSAL 7/20 2/21 Develop Solicitation Package 7/20 9/20 RFP Advertisement 9/20 11/20 Evaluations 11/20 12/20 Selection 12/20 1/21 Contract Award 1/21 2/21 Fully Executed Contract 2/21 2/21 PLANNING 2/21 8/21 Coordinate with LA County for regional system compatibility and integration 2/21 Until end of project Review and Data Collection 2/21 5/21 Prepare Design Criteria/Requirements, including coordination with LACO for regional system compatibility and integration 2/21 8/21 PA&ED 2/21 2/22 Prepare IS, if applicable MND, finalize environmental approval 2/21 2/22 PSH 2/21 8/22 Preliminary PS&E 2/21 10/21 Final PS&E 10/21 8/22 JURISDICTIONAL REVIEW, APPROVALS, AND PERMITS 3/22 12/22 Local Agencies 3/22 12/22 Caltrans 3/22 12/22 CONSTRUCTION 1/23 10/24 PS&E Bid Package Advertisement 1/23 3/23 Contract Award 4/23 5/23 Fully Executed Contract 5/23 5/23 Construction 6/23 7/24 Punch list allowance during System Integration and Testing 8/24 10/24 System Integration and Testing 8/24 10/24 Rev: 05.03.19 4 FA Measure R Hwys Gen Attachment C Scope of Work FTIP #: LA9918871 ATTACHMENT C — Location Map(s) PROJECT LOCATION MAP Q Project#: MR4.1.2.08 FA# 9200000000MR41208 Rev: 05.03.19 5 FA Measure R Hwys Gen Attachment C Scope of Work FTIP M LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 OWiden east side of Rosemead Boulevard to add an exclusive right turn lane from NB Rosemead Boulevard to WB I-10 Freeway easterly On Ramp. OAdd an additional lane for the I-10 Freeway easterly WB Off Ramp. QAdd an exclusive right turn lane from WB Glendon Way to NB Rosemead Boulevard. OEliminate left turn lane frorn I-10 Freeway westerly WB Off -Ramp to WB Glendon Way. OIf determined to be feasible after fiu:ther engineering analysis, widen west side of Rosemead Boulevard to provide a wider right turn lane (current right turn lane is approx. 10' wide, which is narrow). Widening this right turn lane by 1' or 2' (which will require narrowing the sidewalk, accordingly) would improve the traffic flow. QReconfigure geometric aligmnent of west approach on Glendon Way west of Rosemead Boulevard and provide a left turn lane for from WB Glendon Way to WB I-10 Freeway westerly On Ramp. OWiden south-west corner of Glendon Way and I-10 WB westerly On-ramp to provide proper right turn lane and curb return to accommodate right turn traffic onto the ramps. Rev: 05.03.19 G FA Measure R Hwys Gen Attachment C Scope of Work .K� -. r'� � IJJIP lif i" 11` ■1 l� . LMR �1u1 {� ` Mo NOW � r r •r "�� I � I r �• 1 f 1, � l:r t •- «• tie INI i � I I r•�lRi W.1 1 .1■p ,0 I a FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 FA ATTACHMENT D PROJECT REPORTING & EXPENDITURE GUIDELINES REPORTING PROCEDURES Quarterly Progress/Expenditure Report (Attachment D-2) are required for all projects. The GRANTEE shall be subject to and comply with all applicable requirements of the funding agency regarding project -reporting requirements. In addition, GRANTEE will submit the Quarterly Expenditure Report to the LACMTA, after receiving LACMTA Project Manager's acceptance of the draft report, at ACCOUNTSPAYABLE@METRO.NET or by mail to Los Angeles Metropolitan Transportation Authority, Accounts Payable, P. O. Box 512296, Los Angeles, California 90051.0296. Please note that letters or other forms of documentation may not be substituted for this forin. • The Quarterly Progress/ Expenditure Report covers all activities related to the project and lists all costs incurred. It is essential that GRANTEE provides complete and adequate response to all the questions. The expenses listed must be supported by appropriate documentation with a clear explanation of the purpose and relevance of each expense to the project. • In cases where there are no activities to report, or problems causing delays, clear explanation, including actions to remedy the situation, must be provided. • GRANTEE is required to track and report on the project schedule. LACMTA will monitor the timely use of funds and delivery of projects. Project delay, if any, must be reported each quarter. • The draft Quarterly Progress/Expenditure Report is due to the LACMTA as soon as possible after the close of each quarter, but no later than the following dates for each fiscal year: Qual tel- Report Due Date July —September November 30 October - December February 28 January - March May 31 April - June August 31 LACMTA Project Manager shall review and respond in writing to the draft Quarterly Expenditure Report within thirty (3 0) calendar days from receipt. Rev: 02.13.2020 FA Measure R Hwys Gen Attachment D Project Reporting & Expenditure Guidelines FTIP #: LA9918871 Project#: MR4.1.2.08 FA# 9200000000MR41208 Upon completion of the Project a final report that includes project's final evaluation must be submitted. EXPENDITURE GUIDELINES • Any activity or expense charged above and beyond the approved Scope of Work (FA Attachment C) is considered ineligible and will not be reimbursed by the LACMTA unless prior written authorization has been granted by the LACMTA Chief Executive Officer or his/her designee. • Any expense charged to the grant must be clearly and directly related to the project. Administrative cost is the ongoing expense incurred by the GRANTEE for the duration of the project and for the direct benefit of the project as specified in the Scope of Work (Attachment C). Examples of administrative costs are personnel, office supplies, and equipment. As a condition for eligibility, all costs must be necessary for maintaining, monitoring, coordinating, reporting and budgeting of the project. Additionally, expenses must be reasonable and appropriate to the activities related to the project. • LACMTA is not responsible for, and will not reimburse any costs incurred by the GRANTEE prior to the Effective Date of the FA, unless written authorization has been granted by the LACMTA Chief Executive Officer or his/her designee. DEFINITIONS Allowable Cost: To be allowable, costs must be reasonable, recognized as ordinary and necessary, consistent with established practices of the organization, and consistent with industry standard of pay for work classification. • Excessive Cost: Any expense deemed "excessive" by LACMTA staff would be adjusted to reflect a "reasonable and customary" level. For detail definition of "reasonable cost", please refer to the Federal Register OMB Circulars A-87 Cost principals foi• State and Local GovelnmenIs; and A-122 Cost principals fol- Nonprofit Organizations. • Ineligible Expenditures: Any activity or expense charged above and beyond the approved Scope of Work is considered ineligible. Rev: 02.13.2020 FA Measure R Hwys Gen Attachment D Project Reporting & Expenditure Guidelines LACMTA FA MEASURE RATTACH MENT D•2 QUARTERLY PROGRESS / EXPENSE REPORT GRANTEES ARE REQUESTED TO EMAIL THIS REPORT TO ACCOUNTSPAYABLE@ METRO.NET or submit by mail to: Los Angeles County Metropolitan Transportation Authority Accounts Payable P. O. Box 512296 Los Angeles, California 90051-0296 after the close of each quarter, but no later than November 30. February 28, May 31 and August 31. Please note that letters or other forms of documentation may not be substituted for this forth. Refer to the Reporting and Expenditure Guidelines (Attachment D) for further information. Grantee To Complete Invoice # Invoice Date FA# 9200000000MR41208 SECTIONQUARTERLY EXPENSE REPORT Please itemize grant -related charges for this Quarter on Page 5 of this report and include totals in this Section. Rev: 05.03.19 1 FA Measure R Hwys Gen Attachment D•2 Quarterly Report LACMTA Measure R Grant $ QuarterProject This Quarter Expenditure Retention Amount Net Invoice Amount (Less Retention) Project -to -Date Funds Expended to Date (Include this Quarter) Total Project Budget of Project Budget Expended to Date Balance Remaining Rev: 05.03.19 1 FA Measure R Hwys Gen Attachment D•2 Quarterly Report SECTION •R • PROJECT TITLE: I-10/Rosemead Boulevard Freeway [Westbound] Ramp Improvements FA #: 9200000000MR41208 QUARTERLY REPORT SUBMITTED FOR: Fiscal Year: 2014.2015 2015-20162016.2017 2017.2018 2018-2019 2019.2020 Quarter: F]Ql: Jul - Sep F__JQ2: Oct - Dec E]Q3: Jan - Mar F_JQ4: Apr- Jun DA'Z'E SUBMI'1'111): LACMTA MODAL CATEGORY: O RSTI F-1 Pedestrian ❑ TDM ❑ Bicycle Transit Name: LACMTA Project Manager IPlione Number: Project Sponsor Contact / Project Manager Contact Name: Job Title: Mailing Address: Phone Number— E-mail: Signal Synchronization Goods Movement Julio Perucho (213) 922-4387 EcruchnTnG Inelro net Christopher Dast6 Director of Public Works Public Works City of Rosemead East Valley Boulevard, Rosemead, CA 91770 569-2158 Rev: 05.03.19 2 FA Measure R Hwys Gen Attachment D-2 Quarterly Report 1. DELIVERABLES & MILESTONES List all delis eiables and milestones as stated in the FA, with start and end dates. Calculate the total project duration. DO NOT CHANGE THB ORIGINAL FA MILESTONBSTARTAND BND DATES SHOWNINTHE2ND AND 3RD COLUMNSBBLOIV Grantees nmstmake every effort to accmateli, portrayntlestoiie dates in the original FA Scope of Work, since this willprovide ide die basis for calculate}1g any project dela): if milestone start and/or end dates change from those stated in the Original FA Scope of Work, indicate die nen, dates urnderActual Schedule belowand re•calcrdate the project duration. However, this does not change die original milestones iii J our PA. PER YOUR FA AGREEkIENT, ANY CHANGES TO THE PROJECT SCHEDULE i11UST BE FORit/ALLYSUBMITTED UNDER SEPARATE, COVER TOLACMTAFOR 1ffRITTBNCONCURRENCE. FA Milestones Original FA Schedule in Scope of Work Actual Schedule Start Date End Date Start Date End Date Environmental Clearance Design Bid & Award Design Right -of -Way Acquisition Construction Bid & Award Ground Breaking Event Construction Ribbon Cutting Event Total Project Duration (Months) 2. PROJECT COMPLETION A. Based on the comparison of the original and actual project milestone schedules above, project is (select only one) : 1-1Onschedule per original FA schedule ❑ Between 12-24 months behind original schedule ❑ Less than 12 months behind original schedule More than 24 months behind original schedule B. Was the project design started within G mouths of the date originally stated in the FA? F] Yes [:] No n Not Applicable C. Was a construction contract or capital purchase executed within 9 months after completion of design / specifications? F Yes [—] No F] Not Applicable Rev: 05.03.19 3 FA Measure R Hwys Gen Attachment D-2 Quarterly Report 3. TASKS / MILESTONES ACCOMPLISHED List tasks or milestones accomplished and progress made this quarter. 4. PROJECT DELAY If project is delayed, describe reasons for delay (this quarter). Pay particular attention to schedule delays. If delay is for the same reason as mentioned in previous quarters, please indicate by writing "Same as Previous Quarter". 5. ACTION ITEMS TO RESOLVE DELAY If the project is delayed (as described in #4), include action items that have been, or will be, undertaken to resolve the delay. Rev: 05.03.19 4 FA Measure R Hwys Gen Attachment D-2 Quarterly Report SECTION 'D LISTING OF 0 CHARGES THIS QUARTER All expenses and charges must be itemized and listed below. Each iteral listed must be verifiable by an invoice and/or other proper documentation. The total amounts shown here must be equal to this quarter's expenditures listed on page 1 of this report. All expenses and charges must be reflective of the approved budget and rates as shown in the FA Attachment B, Scope of Work. Use additional pages if needed. ITEM INVOICE # TOTAL EXPENSES CHARGED TO LACMTA MEASURE R GRANT 1 2 3 4 5 6 7 8 9 10 11 12 13 TOTAL Note: All receipts, invoices, and time sheets, attached and included with this Expense Report must be listed and shown tinder the Invoice Number column of the Itemized Listing (above). Invoice Payment Information: LACMTA will snake all disbursements electronically unless an exception is requested in writing. ACH Payments require that you complete an ACH Request Form and fax it to Accounts Payable at 213.922-6107. ACH Request Forms can be found at nvww.nnetro.net/callforprojects. Written exception requests for Check Payments should be completed and faxed to Accounts Payable at 213.922.6107. I certify that I ant the responsible Project Manager or fiscal officer and representative of and that to the best of my knlowledge and belief the information stated in this report is true and correct. Signature Name Title Rev: 05.03.19 5 FA Measure R Hwys Gen Attachment D-2 Quarterly Report ATTACHMENT E - FTIP PROJECT SHEET Los Angeles Metropolitan Transportation Authority 2019 Federal Transportation Improvement Program ($000) Project Description: Improve I-10 freeway WB on -8 off -ramps at Rosemead Blvd and Glendon Way- Add RT lane from NB SCAG RTP Pro ecl #: Sludy:N/A Is f�odel: Model M Rosemead Blvd to WB 1-10 on-ramp; add lane for 1-10 easterly WB off -ramp; remove LT lane from 1-10 westerly WB off -ramp PM: All Cayir - (714)883-8877 to WB Glendon Way, widen Rosemead Blvd to allow wider RT lane; reconfigure alignment of west approach on Glendon Way to provide LT lane from WB Glendon Way to WB I-10 westerly on-ramp; widen SW comer of Glendon Way and 1.10 WB westerlyLS: N LS GROUP#: on-ramp. Conformity Category. System :Slate Hwy Roule:10 Postmile: Distance: Phase: No Project Activity Completion Dale 10/30/2024 Lane ff Exld: Lane # Prop: ImpryDesc: A -Ir Basin: SCAB Envir Doc: - Toll Rate: Toll Cole Loc: Toll Method: Hov acs eg loc: Liza: Los Angeles -Long Sub -Area: Sub -Region: San Gabriel Valley 0.00 Beach -Santa Ana COG CTIPS ID: EA#: PPNO: Program Code: RAMPS 7 MODIFYMNE ADDITIONS Slop Loc: PHASE PRIOR 18/19 19/20 20/21 21/22 22123 23/24 BEYOND PROG TOTAL MR20H - Measure R 2Deh Highway PE $300 $500 $50 $0 $850 RW $0 50 S0 SO $0 CON 50 S(t eun 2e ann can ec .en -General Comment: -Modeling Comment: -TCM Comment: -Amendment Comment: -CMP Comment: - Narrative: TOTAL PE: $860 TOTAL RW: $0 TOTAL CON: $6,160 TOTAL PROGRAMMED: $6,000 Change reason:NEW PROJECT Total Project Cost $6,000 Page 1 Thursday, April 2, 2020 FTIP #: LA9918871 ATTACHMENT F BOND REQUIREMENTS Project#: MR4.1.2.08 FA# 9200000000MR41208 The provisions of this Attachment F apply only if and to the extent some or all of the Funds are derived from LACMTA issued Bonds or other debt, the interest on which is tax exempt for federal tax purposes (collectively, the "Bonds"). GRANTEE acknowledges that some or all of the Funds may be derived from Bonds, the interest on which is tax-exempt for federal tax purposes or with respect to which LACMTA receives a Federal subsidy for a portion of the interest cost or the investor receives a tax credit. GRANTEE further acknowledges its understanding that the proceeds of the Bonds are subject to certain ongoing limitations relating to the use of the assets financed or provided with such proceeds ("Project Costs" or "Project Components") in the trade or business of any person or entity other than a governmental organization (any such use by a person or entity other than a governmental organization is referred to as "Private Use"). Private Use will include any sale, lease or other arrangement pursuant to which a nongovernmental person or entity receives a legal entitlement of a Project Component and also includes certain agreements pursuant to which a nongovernmental person will operate or manage a Project Component. Each quarterly invoice submitted by GRANTEE to reimburse prior expenditures (or to be received as an advance) shall provide information regarding the specific Project Costs or Project Components to which the Funds which pay that invoice will be allocated and whether there is or might be any Private Use associated with such Project Costs or Project Components. GRANTEE will, for the entire time over which LACMTA's Bonds or other debt remains outstanding, (1) notify and receive LACMTA' s approval prior to entering into any arrangement which will or might result in Private Use and (2) maintain records, including obtaining records from contractors and subcontractors as necessary, of all allocations of Funds to Project Costs or Project Components and any Private Use of such Project Costs or Project Components in sufficient detail to comply and establish compliance with Section 141 of the Internal Revenue Code of 1986, as amended (the "Code"), or similar code provision then in effect and applicable, as determined by the LACMTA in consultation with its bond counsel. GRANTEE will designate one or more persons that will be responsible for compliance with the obligations described in this Attachment F and notify LACMTA of such designations. Rev: 05.15.19 1 FA Measure R Hwys Gen Attachment F Bond Requirements FTIP #: LA9918871 ATTACHMENT G SPECIAL GRANT CONDITIONS Project#: MR4.1.2.08 FA# 9200000000MR41208 With regards to Part II, Paragraph 7, the following shall also apply: a. Funds allocated for each SR -710 North Mobility Improvement Project [MIP] shall be on a one-time basis. LACMTA shall not fund any cost increase. Potential cost savings shall remain in the Corridor and shall be assigned to other projects consistent with the purpose of the program as determined by LACMTA. b. Grantee is responsible for all cost overruns incurred. Under no circumstances will the total amount of money that LACMTA reimburses the Grantee exceed the amount of Funds approved by LACMTA. c. LACMTA shall reimburse Grantee up to a maximum amount of $6,000,000 as specified for the Project subject to the terms and conditions contained herein. d. LACMTA shall transfer the Funds to the Grantee on a reimbursement basis only. No advance of Funds shall be allowed. 2. With regards to Part II, Paragraph 8.2, the following shall also apply: a. LACMTA shall not be obligated to program additional fiends to the Project. 3. Grantee shall conduct Before and After Studies to evaluate and document the results of project implementation in terms of congestion relief and air quality improvements. a. Grantee shall maintain proper records of the existing conditions before and after each MIP to assess the performance of the completed MIP as well as the overall program. b. A copy of the Before and After Study shall be submitted to LACMTA within six months of completion of the project construction. Rev: 05.03.19 1 FA Measure R Hwys Gen Attachment G Special Grant Conditions